Last updated: 18-09-25
Bank Deposit (Preferred):
Account Name: Creative Boolean Routine Pty Ltd
BSB: 082-356
Account: 708188598
PayID: accounts@creativus-design.com
Other Options:
See your online invoice for other available payment methods and their associated fees.
A late fee of 10% of the invoice total may apply if payment is not received within 7 days of the due date. Creativus Design reserves the right to waive or adjust this at its discretion.
Quoted prices cover the agreed scope of work only. Any changes or additional work (including added features, extra time, or out-of-scope revisions) will be quoted and approved by you before we proceed.
Website, content and design projects include revisions as agreed in your proposal. Excessive or additional revisions may incur extra charges.
Final deliverables become the client’s property once full payment has been received. Creativus Design retains ownership of source files, development tools, proprietary strategies, and internal systems unless otherwise agreed in writing.
Accounts registered in the client’s name (e.g. domain names, social media profiles) are owned by the client, who can request access or transfer at any time.
If you are on a maintenance plan:
Either party may end services with 30 days’ written notice. All outstanding invoices must be paid before termination. No refunds will be provided for completed work or milestone payments. Work already delivered or partially completed up to the date of termination will be invoiced accordingly.
Our total liability is limited to the amount paid for the service. We are not liable for any indirect, consequential, or third-party losses.
Timely delivery of content, feedback, and approvals is required to keep work on track. Delays from the client may affect delivery dates or incur additional charges.
We aim to keep services live and respond within a reasonable time during business hours. You can email your account manager directly or contact support@creativus-design.com if unavailable.
Creativus Design manages your project data on your behalf. The client is also responsible for retaining their own copies and backups. You may request a data export at any time during or after your engagement.
We treat all client information as confidential and will not share it unless required by law.
Creativus Design may adjust pricing for ongoing or recurring services once per year to reflect inflation, increased operating costs, or changes in market conditions. You will receive at least 30 days’ written notice before any price changes take effect.
If a dispute arises, both parties agree to first attempt to resolve the issue in good faith through discussion or mediation before taking legal action.
We are not liable for delays or failures caused by events beyond our control, including natural disasters, power outages, internet disruptions, pandemics, or actions by third parties.
These terms are governed by the laws of New South Wales and the Commonwealth of Australia. Any disputes will be handled in the courts of New South Wales.
You agree to indemnify and hold Creativus Design harmless from any claims, damages, or expenses (including legal fees) that may arise from your use of the work we provide or any content you provide to us.
By paying an invoice, approving a quote, or otherwise engaging our services, you accept these Terms and Conditions. Any objections must be raised in writing before work begins or during the course of the project.